KING, Circuit Judge: In this contract action, plaintiff-appellant is a contractor seeking damages for extra work and delay costs incurred performing land improvement for a residential development in Harris County, Texas. The district court granted summary judgment to defendants-appellees, holding that plaintiff-appellant’s claims were barred by waivers and releases it executed m…
Read the full opinion (source) ↗
Lexace provides legal information, not legal advice, and no attorney–client relationship is created. Citation figures are counts of later citing opinions in our corpus and may be incomplete; always read and Shepardize the full opinion before relying on it.